Call Support 1300 035 483
   Working Hours
Mon - Thur 8.45am - 4pm. Fri 8.45am - 2pm

Terms & Conditions

   Call Us On 1300 035 483

1. Definitions
1.1 “Contract” means the terms and conditions contained herein, together with any Quotation, order, invoice or other document or amendments expressed to be supplemental to this Contract.
1.2 “Contractor” means Elite Shower Repairs Pty Ltd, its successors and assigns or any person acting on behalf of and with the authority of Elite Shower Repairs Pty Ltd.
1.3 “Client” means the person/s, entities or any person acting on behalf of and with the authority of the Client requesting the Contractor to provide the Works as specified in any proposal, quotation, order, invoice or other documentation, and:
(a) if there is more than one Client, is a reference to each Client jointly and severally; and
(b) if the Client is a partnership, it shall bind each partner jointly and severally; and
(c) if the Client is a part of a Trust, shall be bound in their capacity as a trustee; and
(d) includes the Client’s executors, administrators, successors and permitted assigns.
1.4 “Works” means all Works (including consultation, manufacturing and/or installation services) or Materials supplied by the Contractor to the Client at the Client’s request from time to time (where the context so permits the terms ‘Works’ or ‘Materials’ shall be interchangeable for the other).
1.5 “Worksite” means the address nominated by the Client to which the Materials are to be supplied by the Contractor.
1.6 “Intended Use” means a product and the use thereof, for which the product is intended to be, or is reasonably likely to be, associated with the Works.
1.7 “Non-Conforming Building Product” means building products that are regarded as Non-Conforming for an Intended Use if, when associated with a building:
(a) the product is not, or will not be, safe; or
(b) does not, or will not, comply with the relevant regulatory provisions; or
(c) the product does not perform, or is not capable of performing, for the use to the standard it is represented to conform by or for a person in the chain of responsibility for the product.
1.8 “Confidential Information” means information of a confidential nature whether oral, written or in electronic form including, but not limited to, this Contract, either party’s intellectual property, operational information, know-how, trade secrets, financial and commercial affairs, contracts, client information (including but not limited to, “Personal Information” such as: name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) and pricing details.
1.9 “Cookies” means small files which are stored on a user’s computer. They are designed to hold a modest amount of data (including Personal Information) specific to a particular client and website, and can be accessed either by the web server or the client’s computer. If the Client does not wish to allow Cookies to operate in the background when ordering from the website, then the Client shall have the right to enable / disable the Cookies first by selecting the option to enable / disable provided on the website, prior to ordering Works via the website.
1.10 “Price” means the Price payable (plus any GST where applicable) for the Works as agreed between the Contractor and the Client in accordance with clause 5 below. 1.11 “GST” means Goods and Services Tax as defined within the “A New Tax System (Goods and Services Tax) Act 1999” (Cth).

2. Acceptance
2.1 The Client is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Client places an order for or accepts delivery of any Works.
2.2 In the event of any inconsistency between the terms and conditions of this Contract and any other prior document or schedule that the parties have entered into, the terms of this Contract shall prevail.
2.3 Any amendment to the terms and conditions contained in this Contract may only be amended in writing by the consent of both parties.
2.4 The Client acknowledges that the supply of Works on credit shall not take effect until the Client has completed a credit application with the Contractor and it has been approved with a credit limit established for the account.
2.5 In the event that the supply of Works request exceeds the Clients credit limit and/or the account exceeds the payment terms, the Contractor reserves the right to refuse delivery.
2.6 Subject to clause 2.5, should the Client have any issues regarding payment of the account in accordance with clause 5.5, the Client shall advise the Contractor as soon as possible so a payment arrangement can be made.
2.7 Electronic signatures shall be deemed to be accepted by either party providing that the parties have complied with Section 9 of the Electronic Transactions Act 2000 (NSW), or Section 14 of the Electronic Transactions (Queensland) Act 2001, (whichever is applicable), or any other applicable provisions of that Act or any Regulations referred to in that Act.
2.8 Where the Contractor gives any advice, recommendation, information, assistance or service provided by the Contractor in relation to Materials or Works supplied (including, but not limited to, the suitability of the Worksite or a particular course of action, etc.), such is given in good faith to the Client, or the Client’s agent and is based on the Contractor’s own knowledge and experience and shall be accepted without liability on the part of the Contractor. Where such advice or recommendations are not acted upon then the Contractor shall require the Client or their agent to authorise commencement of the Works in writing. The Contractor shall not be liable in any way whatsoever for any damages or losses that occur after any subsequent commencement of the Works.
2.9 The Client acknowledges and accepts that if a defect is not covered by the warranty as detailed in the Contractor’s Warranty Against Defects form and the Contractor has been requested to return to the Worksite and/or perform repairs, that a call-out fee may be applicable and that any repairs will be charged for at the Contractor’s normal hourly rate plus any Materials.

3. Errors and Omissions
3.1 The Client acknowledges and accepts that the Contractor shall, without prejudice, accept no liability in respect of any alleged or actual error(s) and/or omission(s):
(a) resulting from an inadvertent mistake made by the Contractor in the formation and/or administration of this Contract; and/or
(b) contained in/omitted from any literature (hard copy and/or electronic) supplied by the Contractor in respect of the Works.
3.2 In the event such an error and/or omission occurs in accordance with clause 3.1, and is not attributable to the negligence and/or wilful misconduct of the Contractor; the Client shall not be entitled to treat this Contract as repudiated nor render it invalid.

4. Change in Control
4.1 The Client shall give the Contractor not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client and/or any other change in the Client’s details (including but not limited to, changes in the Client’s name, address, contact phone or fax number/s, change of trustees, or business practice). The Client shall be liable for any loss incurred by the Contractor as a result of the Client’s failure to comply with this clause.

5. Price and Payment
5.1 At the Contractor’s sole discretion the Price shall be either:
(a) as indicated on invoices provided by the Contractor to the Client in respect of Works performed or Materials supplied; or
(b) the Price as at the date of delivery of the Works according to the Contractor’s current price list; or
(c) the Contractor’s quoted Price (subject to clause 5.2) which shall be binding upon the Contractor provided that the Client shall accept the Contractor’s quotation in writing within thirty (30) days.
5.2 The Contractor reserves the right to change the Price:
(a) if a variation to the Materials which are to be supplied is requested; or
(b) if a variation to the Works originally scheduled (including any applicable plans or specifications) is requested; or
(c) where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, poor weather conditions, limitations to Worksite access, latent Worksite defects, safety considerations and/r health hazards (such as the discovery of asbestos or other toxic materials, etc.), prerequisite work by a third party not being completed, lack of required utilities, remedial work required due to existing workmanship being of a poor quality or non-compliant to the building code, inaccurate measurements, plans or specifications supplied by the Client, or hidden pipes and wiring, etc.) which are only discovered on commencement of the Works; or
(d) in the event of increases to the Contractor in the cost of labour or Materials which are beyond the Contractor’s control.
5.3 Variations will be charged for on the basis of the Contractor’s quotation, and will be detailed in writing, and shown as variations on the Contractor’s invoice. The Client shall be required to respond to any variation submitted by the Contractor within ten (10) working days. Failure to do so will entitle the Contractor to add the cost of the variation to the Price. Payment for all variations must be made in full at the time of their completion.
5.4 At the Contractor’s sole discretion a non-refundable deposit may be required. 5.5 Time for payment for the Works being of the essence, the Price will be payable by the Client on the date/s determined by the Contractor, which may be:
(a) on completion of the Works; or
(b) by way of progress payments in accordance with the Contractor’s specified progress payment schedule. Such progress payment claims may include the reasonable value of authorised variations and the value of any Materials delivered to the site but not yet installed; or
(c) seven (7) days following the end of the month in which a statement is delivered to the Client’s address or address for notices;
(d) the date specified on any invoice or other form as being the date for payment; or (e) failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Client by the Contractor.
5.6 Payment may be made by cash, bank cheque, electronic/on-line banking, credit card (a surcharge may apply per transaction), or by any other method as agreed to between the Client and the Contractor.
5.7 The Contractor may in its discretion allocate any payment received from the Client towards any invoice that the Contractor determines and may do so at the time of receipt or at any time afterwards. On any default by the Client the Contractor may re-allocate any payments previously received and allocated. In the absence of any payment allocation by the Contractor, payment will be deemed to be allocated in such manner as preserves the maximum value of the Contractor’s Purchase Money Security Interest (as defined in the PPSA) in the Materials.
5.8 The Client shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Client by the Contractor nor to withhold payment of any invoice because part of that invoice is in dispute.
5.9 Unless otherwise stated the Price does not include GST. In addition to the Price, the Client must pay to the Contractor an amount equal to any GST the Contractor must pay for any supply by the Contractor under this or any other contract for the sale of the Materials. The Client must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Client pays the Price. In addition, the Client must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.

6. Provision of the Works
6.1 Subject to clause 6.2 it is the Contractor’s responsibility to ensure that the Works start as soon as it is reasonably possible.
6.2 The Works’ commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that the Contractor claims an extension of time (by giving the Client written notice) where completion is delayed by an event beyond the Contractor’s control, including but not limited to any failure by the Client to:
(a) make a selection; or
(b) have the site ready for the Works; or
(c) notify the Contractor that the site is ready.
6.3 At the Contractor’s sole discretion, the cost of delivery is included in the Price.
6.4 The Contractor may deliver the Works by separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions in these terms and conditions.
6.5 Any time specified by the Contractor for delivery of the Works is an estimate only and the Contractor will not be liable for any loss or damage incurred by the Client as a result of delivery being late. However both parties agree that they shall make every endeavour to enable the Works to be supplied at the time and place as was arranged between both parties. In the event that the Contractor is unable to supply the Works as agreed solely due to any action or inaction of the Client, then the Contractor shall be entitled to;
(a) charge a fee for re-supplying the Works at a later time and date, and/or for storage of the Materials; or
(b) subject to clause 17, terminate the Contract.

7. Risk
7.1 If the Contractor retains ownership of the Materials under clause 11 then:
(a) where the Contractor is supplying Materials only, all risk for the Materials shall immediately pass to the Client on delivery and the Client must insure the Materials on or before delivery. Delivery of the Materials shall be deemed to have taken place immediately at the time that either:
(i) the Client or the Client’s nominated carrier takes possession of the Materials at the Contractor’s address; or
(ii) the Materials are delivered by the Contractor or the Contractor’s nominated carrier to the Client’s nominated delivery address (even if the Client is not present at the address).
(b) where the Contractor is to both supply and install Materials then the Contractor shall maintain a contract works insurance policy until the Works are completed. Upon completion of the Works all risk for the Works shall immediately pass to the Client. The Contractor shall have Public Liability Insurance of at least five million dollars ($5m); it is the Client’s responsibility to ensure that they are similarly insured.
7.2 Notwithstanding the provisions of clause 7.1 if the Client specifically requests the Contractor to leave Materials outside the Contractor’s premises for collection or to deliver the Materials to an unattended location then such materials shall always be left at sole risk of the Client and it shall be the Client’s responsibility to ensure the Materials are insured adequately or at all. In the event that such Materials are lost, damaged or destroyed then replacement of the Materials shall be at the Client’s expense.
7.3 The Client warrants that the structure of the premises or equipment in or upon which these Materials are to be installed or erected is sound and will sustain the installation and Works incidental thereto and the Contractor shall not be liable for any claims, demands, losses, damages, costs and expenses howsoever caused or arising should the premises or equipment be unable to accommodate the installation.
7.4 The Contractor shall be entitled to rely on the accuracy of any plans, specifications and other information provided by the Client. The Client acknowledges and agrees that in the event that any of this information provided by the Client is inaccurate, the Contractor accepts no responsibility for any loss, damages, or costs however resulting from these inaccurate plans, specifications or other information.
7.5 All potential waterproofing surfaces are subject to an inspection by the Contractor prior to the commencement of the Works. In the event that the surface is deemed unsuitable, then the Contractor reserves the right to halt the Works until such time as it is agreed between the Contractor and the Client as to the additional cost in further preparation of the surface in order to make it fit for waterproofing. The additional cost shall be charged as a variation to the quotation as per clause 5.2.
7.6 The Contractor shall not be liable for any defect in the Works if the Client does not follow the Contractor’s recommendations, including that the shower should not be used for a minimum of twelve (12) hours.
7.7 Whilst the Contractor will take all due care during Works however the Contractor will not accept any responsibility for any chipping, scratches, cracking or breaking of any existing tiles, shower screens (including factory seals, fittings and tapware) that may occur during provision of the Works.
7.8 The Client acknowledges that;
(a) the Contractor is only responsible for Materials that are repaired by the Contractor, and in the event that other components subsequently fail, the Client agrees to indemnify the Contractor against any loss or damage to the Works, or caused by the Materials, or any part thereof howsoever arising;
(b) Materials supplied may:
(i) fade or change colour over time; and
(ii) expand, contract or distort as a result of exposure to heat, cold, weather; and
(iii) mark, stain or become discoloured overtime if exposed to certain substances (including, but not limited to, cleaning and/or personal care products).
7.9 The Contractor accepts no responsibility for:
(a) any defective operation of Materials that is caused through structural or substrate movement upon which the Materials were applied which is beyond the Contractor’s control (including bleed black or leeching, growth of mould or where the bath or shower moves away from the walls); or
(b) leaks that are incorrectly diagnosed by any other party prior to the commencement of the Works; or
(c) plumbing, tiling, shower screen or any other Works required for the restoration or making good of any surface/area where any Works have been carried out.
7.10 The Client agrees to indemnify the Contractor from any damage caused by either the Client, the Client’s agent or any other third party during and after the completion of the Works (including but not limited to damage to plumbing, tiling, mould, timber, carpet, gyprock, or painting, etc.). If the Client instructs the Contractor to rectify any damage caused, will become a variation to the original quotation and will be charged at the Contractor normal hourly rate.

8. Client’s Responsibilities
8.1 It is the intention of the Contractor and agreed by the Client that it is the responsibility of the Client to:
(a) ensure that:
(i) the Contractor has clear and free access to the Worksite at all times to enable them to undertake the Works (including carrying out Worksite inspections, gain signatures for required documents, and for the delivery and installation of the Materials). The Contractor shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of the Contractor; and
(ii) any surface requiring waterproofing is suitable for the purpose. In the event that the Client requests the Contractor to prepare the surface for waterproofing, then at the Contractor’s sole discretion a fee shall be charged for the Works, and shall become immediately due and payable; and
(iii) no other trades men work on the membrane applied to the surface, until the membrane is fully dried and cured to manufacturer’s specifications. The Contractor shall not be liable for any costs, damages or loss however arising from the Client’s failure to comply with this clause; and
(iv) tiling or adding backfill is delayed until the waterproof has cured in accordance to the manufacturer’s specifications. Failure to adhere to this clause will mean the Contractor shall not be liable for any costs, damages or losing arising; and
(v) subsequent Works (such as tiling, etc.) must be completed in a timely manner; any delay may deteriorate the membrane and may void any applicable warranty; and
(b) provide the Contractor, while at the Worksite, with adequate access to any utilities/facilities required in order for the Contractor to complete the Works (including, but not limited to, free power source, water, safety lighting, and toilet facilities, etc.); and
(c) make the premises available on the agreed date and time and have all areas clean and clear to enable scheduled work to be completed in accordance with the schedule of installation. If installation is interrupted due to the failure of the Client to adhere to the installation schedule agreed to between the Contractor and the Client, any additional costs will be invoiced to the Client as variation in accordance with clause 5.2;
8.2 The Client agrees to be present at the Worksite when and as reasonably requested by the Contractor and its employees, contractors and/or agents. 8.3 The Contractor is not insured to remove furniture or fittings and will not do so, nor is the Contractor licensed to move gas or electrical appliances.

9. Underground Locations
9.1 Prior to the Contractor commencing the Works the Client must advise the Contractor of the precise location of all underground mains/services on the Worksite and clearly mark the same. The mains/services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, communication cables, fibre optic cables, oil pumping mains, and any other services that may be on the Worksite.
9.2 Whilst the Contractor will take all care to avoid damage to any services the Client agrees to indemnify the Contractor in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 9.1.

10. Compliance with Laws
10.1 The Client and the Contractor shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the Works, including any work health and safety (WHS) laws and any other relevant safety standards or legislation.
10.2 The Client shall obtain (at the expense of the Client) all licenses, permits and approvals that may be required for the Works. 10.3 Worksite Inductions
(a) in the event the Client requires an employee or sub-contractor of the Contractor to undertake a Worksite induction during working hours, the Client will be liable to pay the hourly charges for that period. If any induction is needs to be undertaken prior to the commencement date then the Client shall be liable to pay the Contractor’s standard (and/or overtime, if applicable) hourly labour rate; or
(b) where the Contractor is in control of the Worksite, the Client and/or the Clients third party contractors must initially carry out the Contractor’s Health & Safety induction course before access to the Worksite will be granted. Inspection of the Worksite during the course of the Works will be by appointment only and unless otherwise agreed, in such an event the Client and/or third party acting on behalf of the Client must at all times be accompanied by the Contractor.

11. Title
11.1 The Contractor and the Client agree that ownership of the Materials shall not pass until:
(a) the Client has paid the Contractor all amounts owing to the Contractor; and
(b) the Client has met all of its other obligations to the Contractor.
11.2 Receipt by the Contractor of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.
11.3 It is further agreed that until ownership of the Materials passes to the Client in accordance with clause 11.1:
(a) the Client is only a bailee of the Materials and unless the Materials have become fixtures must return the Materials to the Contractor on request;
(b) the Client holds the benefit of the Client’s insurance of the Materials on trust for the Contractor and must pay to the Contractor the proceeds of any insurance in the event of the Materials being lost, damaged or destroyed;
(c) the production of these terms and conditions by the Contractor shall be sufficient evidence of the Contractor’s rights to receive the insurance proceeds direct from the insurer without the need for any person dealing with the Contractor to make further enquiries;
(d) the Client must not sell, dispose, or otherwise part with possession of the Materials other than in the ordinary course of business and for market value. If the Client sells, disposes or parts with possession of the Materials then the Client must hold the proceeds of any such act on trust for the Contractor and must pay or deliver the proceeds to the Contractor on demand;
(e) the Client should not convert or process the Materials or intermix them with other goods but if the Client does so then the Client holds the resulting product on trust for the benefit of the Contractor and must sell, dispose of or return the resulting product to the Contractor as it so directs;
(f) unless the Materials have become fixtures the Client irrevocably authorises the Contractor to enter any premises where the Contractor believes the Materials are kept and recover possession of the Materials;
(g) the Contractor may recover possession of any Materials in transit whether or not delivery has occurred;
(h) the Client shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials while they remain the property of the Contractor;
(i) the Contractor may commence proceedings to recover the Price of the Materials sold notwithstanding that ownership of the Materials has not passed to the Client.

12. Personal Property Securities Act 2009 (“PPSA”)
12.1 In this clause financing statement, financing change statement, security agreement, and security interest has the meaning given to it by the PPSA.
12.2 Upon assenting to these terms and conditions in writing the Client acknowledges and agrees that these terms and conditions constitute a security agreement for the purposes of the PPSA and creates a security interest in all Materials and/or collateral (account) – being a monetary obligation of the Client to the Contractor for Works – that have previously been supplied and that will be supplied in the future by the Contractor to the Client.
12.3 The Client undertakes to:
(a) promptly sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which the Contractor may reasonably require to:
(i) register a financing statement or financing change statement in relation to a security interest on the Personal Property Securities Register;
(ii) register any other document required to be registered by the PPSA; or
(iii) correct a defect in a statement referred to in clause 12.3(a)(i) or 12.3(a)(ii);
(b) indemnify, and upon demand reimburse, the Contractor for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register established by the PPSA or releasing any Materials charged thereby;
(c) not register a financing change statement in respect of a security interest without the prior written consent of the Contractor;
(d) not register, or permit to be registered, a financing statement or a financing change statement in relation to the Materials and/or collateral (account) in favour of a third party without the prior written consent of the Contractor;
(e) immediately advise the Contractor of any material change in its business practices of selling the Materials which would result in a change in the nature of proceeds derived from such sales.
12.4 The Contractor and the Client agree that sections 96, 115 and 125 of the PPSA do not apply to the security agreement created by these terms and conditions.
12.5 The Client hereby waives its rights to receive notices under sections 95, 118, 121(4), 130, 132(3)(d) and 132(4) of the PPSA.
12.6 The Client waives its rights as a grantor and/or a debtor under sections 142 and 143 of the PPSA.
12.7 Unless otherwise agreed to in writing by the Contractor, the Client waives its right to receive a verification statement in accordance with section 157 of the PPSA.
12.8 The Client shall unconditionally ratify any actions taken by the Contractor under clauses 12.3 to 12.5. 12.9 Subject to any express provisions to the contrary (including those contained in this clause 12), nothing in these terms and conditions is intended to have the effect of contracting out of any of the provisions of the PPSA.

13. Security and Charge
13.1 In consideration of the Contractor agreeing to supply the Materials, the Client charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Client either now or in the future, to secure the performance by the Client of its obligations under these terms and conditions (including, but not limited to, the payment of any money).
13.2 The Client indemnifies the Contractor from and against all the Contractor’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising the Contractor’s rights under this clause.
13.3 The Client irrevocably appoints the Contractor and each director of the Contractor as the Client’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 13 including, but not limited to, signing any document on the Client’s behalf.

14. Defects, Warranties and Returns, Competition and Consumer Act 2010 (CCA)
14.1 The Client must inspect all Materials on delivery (or the Works on completion) and must within forty-eight (48) hours of delivery notify the Contractor in writing of any evident defect/damage, shortage in quantity, or failure to comply with the description or quote. The Client must notify any other alleged defect in the Materials/Works as soon as reasonably possible after any such defect becomes evident. Upon such notification the Client must allow the Contractor to inspect the Materials or to review the Works provided.
14.2 Under applicable State, Territory and Commonwealth Law (including, without limitation the CCA), certain statutory implied guarantees and warranties (including, without limitation the statutory guarantees under the CCA) may be implied into these terms and conditions (NonExcluded Guarantees).
14.3 The Contractor acknowledges that nothing in these terms and conditions purports to modify or exclude the Non-Excluded Guarantees.
14.4 Except as expressly set out in these terms and conditions or in respect of the Non-Excluded Guarantees, the Contractor makes no warranties or other representations under these terms and conditions including but not limited to the quality or suitability of the Materials/Works. The Contractor’s liability in respect of these warranties is limited to the fullest extent permitted by law.
14.5 If the Client is a consumer within the meaning of the CCA, the Contractor’s liability is limited to the extent permitted by section 64A of Schedule 2.
14.6 If the Contractor is required to replace any Materials under this clause or the CCA, but is unable to do so, the Contractor may refund any money the Client has paid for the Materials.
14.7 If the Contractor is required to rectify, re-supply, or pay the cost of re-supplying the Works under this clause or the CCA, but is unable to do so, then the Contractor may refund any money the Client has paid for the Works but only to the extent that such refund shall take into account the value of Works and Materials which have been provided to the Client which were not defective.
14.8 If the Client is not a consumer within the meaning of the CCA, the Contractor’s liability for any defect or damage in the Materials is:
(a) limited to the value of any express warranty or warranty card provided to the Client by the Contractor at the Contractor’s sole discretion;
(b) limited to any warranty to which the Contractor is entitled, if the Contractor did not manufacture the Materials;
(c) otherwise negated absolutely.
14.9 The warranty period shall commence following completion of the Works, provided all monies due and payable are paid to the Contractor. Overdue and/or outstanding monies owed to the Contractor for the any Works and/or Materials supplied by the Contractor under this Contract may render any warranty and guarantee (if applicable), null and void.
14.10 Subject to this clause 14, returns will only be accepted provided that:
(a) the Client has complied with the provisions of clause 14.1; and
(b) the Contractor has agreed that the Materials are defective; and
(c) the Materials are returned within a reasonable time at the Client’s cost (if that cost is not significant); and
(d) the Materials are returned in as close a condition to that in which they were delivered as is possible.
14.11 Notwithstanding clauses 14.1 to 14.9 but subject to the CCA, the Contractor shall not be liable for any defect or damage which may be caused or partly caused by or arise as a result of:
(a) the Client failing to properly maintain or store any Materials;
(b) the Client using the Materials for any purpose other than that for which they were designed;
(c) the Client continuing to use any Materials after any defect became apparent or should have become apparent to a reasonably prudent operator or user;
(d) interference with the Works by the Client or any third party without the Contractor’s prior approval;
(e) the Client failing to follow any instructions or guidelines provided by the Contractor;
(f) grouting or the use of silicone; or
(g) the appearance/finish of the shower; or
(h) staining or discoloration over time directly or indirectly because of cleaning products or personal care products;
(i) bleed back or leeching, growth of mould;
(j) building movement, physical damage and further substrate moving;
(k) variations in thickness or product application due to initial placement of tiles; or
(l) chipping, scratches, cracking or breakage of tiles, shower screen including factory seals, fittings, or tapware resulting from the provision of the Works; or
(m) fair wear and tear, any accident, or act of God;
14.12 In the case of second hand Material, unless the Client is a consumer under the CCA, the Client acknowledges that it has had full opportunity to inspect the second hand Materials prior to delivery and accepts them with all faults and that to the extent permitted by law no warranty is given by the Contractor as to the quality or suitability for any purpose and any implied warranty, statutory or otherwise, is expressly excluded. The Client acknowledges and agrees that the Contractor has agreed to provide the Client with the second hand Materials and calculated the Price of the second hand Materials in reliance of this clause 14.12.
14.13 Notwithstanding anything contained in this clause if the Contractor is required by a law to accept a return then the Contractor will only accept a return on the conditions imposed by that law.
14.14 Subject to clause 14.1, customised, or non-stocklist items or Materials made or ordered to the Client’s specifications are not acceptable for credit or return.

15. Intellectual Property
15.1 Where the Contractor has designed, drawn, written plans or a schedule of Works, or created any products for the Client, then the copyright in all such designs, drawings, documents, plans, schedules and products shall remain vested in the Contractor, and shall only be used by the Client at the Contractor’s discretion. Under no circumstances may such designs, drawings and documents be used without the express written approval of the Contractor.
15.2 The Client warrants that all designs, specifications or instructions given to the Contractor will not cause the Contractor to infringe any patent, registered design or trademark in the execution of the Client’s order and the Client agrees to indemnify the Contractor against any action taken by a third party against the Contractor in respect of any such infringement.
15.3 The Client agrees that the Contractor may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings, plans or products which the Contractor has created for the Client.

16. Default and Consequences of Default
16.1 Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at the Contractor’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.
16.2 Any overdue amounts will immediately incur an administration fee of $66 per 7 days.
16.3 Failure to pay late fees void all warranties.
16.4 If the Client owes the Contractor any money the Client shall indemnify the Contractor from and against all costs and disbursements incurred by the Contractor in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, the Contractor’s contract default fee, and bank dishonour fees).
16.5 Further to any other rights or remedies the Contractor may have under this Contract, if a Client has made payment to the Contractor, and the transaction is subsequently reversed, the Client shall be liable for the amount of the reversed transaction, in addition to any further costs incurred by the Contractor under this clause 16 where it can be proven that such reversal is found to be illegal, fraudulent or in contravention to the Client’s obligations under this Contract.
16.6 Without prejudice to the Contractor’s other remedies at law the Contractor shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled and all amounts owing to the Contractor shall, whether or not due for payment, become immediately payable if:
(a) any money payable to the Contractor becomes overdue, or in the Contractor’s opinion the Client will be unable to make a payment when it falls due;
(b) the Client has exceeded any applicable credit limit provided by the Contractor;
(c) the Client becomes insolvent or bankrupt, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
(d) a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.

17. Cancellation
17.1 Without prejudice to any other remedies the Contractor may have, if at any time the Client is in breach of any obligation (including those relating to payment) under these terms and conditions the Contractor may suspend or terminate the supply of Works to the Client. The Contractor will not be liable to the Client for any loss or damage the Client suffers because the Contractor has exercised its rights under this clause.
17.2 The Contractor may cancel any contract to which these terms and conditions apply or cancel delivery of Works at any time before the Works are commenced by giving written notice to the Client. On giving such notice the Contractor shall repay to the Client any sums paid in respect of the Price, less any amounts owing by the Client to the Contractor for Works already performed. The Contractor shall not be liable for any loss or damage whatsoever arising from such cancellation.
17.3 In the event that the Client cancels the delivery of Works the Client:
(a) must provide written notice to the Contractor no less than forty-eight (48) hours’ prior to the scheduled delivery date; and
(b) shall be liable for any and all loss incurred (whether direct or indirect) by the Contractor as a direct result of the cancellation (including, but not limited to, any loss of profits), notwithstanding that at the Contractor’s sole discretion, where appropriate notice is not received a cancellation fee of one hundred and twenty-five dollars ($125) will apply.
17.4 Cancellation of orders for products made to the Client’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.

18. Privacy Policy
18.1 All emails, documents, images or other recorded information held or used by the Contractor is Personal Information, as defined and referred to in clause 18.3, and therefore considered Confidential Information. The Contractor acknowledges its obligation in relation to the handling, use, disclosure and processing of Personal Information pursuant to the Privacy Act 1988 (“the Act”) including the Part IIIC of the Act being Privacy Amendment (Notifiable Data Breaches) Act 2017 (NDB) and any statutory requirements, where relevant in a European Economic Area (“EEA”), under the EU Data Privacy Laws (including the General Data Protection Regulation “GDPR”) (collectively, “EU Data Privacy Laws”). The Contractor acknowledges that in the event it becomes aware of any data breaches and/or disclosure of the Clients Personal Information, held by the Contractor that may result in serious harm to the Client, the Contractor will notify the Client in accordance with the Act and/or the GDPR. Any release of such Personal Information must be in accordance with the Act and the GDPR (where relevant) and must be approved by the Client by written consent, unless subject to an operation of law.
18.2 Notwithstanding clause 18.1, privacy limitations will extend to the Contractor in respect of Cookies where transactions for purchases/orders transpire directly from the Contractor’s website. The Contractor agrees to display reference to such Cookies and/or similar tracking technologies, such as pixels and web beacons (if applicable), such technology allows the collection of Personal Information such as the Client’s:
(a) IP address, browser, email client type and other similar details;
(b) tracking website usage and traffic; and
(c) reports are available to the Contractor when the Contractor sends an email to the Client, so the Contractor may collect and review that information (“collectively Personal Information”) In order to enable / disable the collection of Personal Information by way of Cookies, the Client shall have the right to enable / disable the Cookies first by selecting the option to enable / disable, provided on the website prior to proceeding with a purchase/order via the Contractor’s website.
18.3 The Client agrees for the Contractor to obtain from a credit reporting body (CRB) a credit report containing personal credit information (e.g. name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) about the Client in relation to credit provided by the Contractor.
18.4 The Client agrees that the Contractor may exchange information about the Client with those credit providers and with related body corporates for the following purposes:
(a) to assess an application by the Client; and/or
(b) to notify other credit providers of a default by the Client; and/or
(c) to exchange information with other credit providers as to the status of this credit account, where the Client is in default with other credit providers; and/or
(d) to assess the creditworthiness of the Client including the Client’s repayment history in the preceding two (2) years.
18.5 The Client consents to the Contractor being given a consumer credit report to collect overdue payment on commercial credit.
18.6 The Client agrees that personal credit information provided may be used and retained by the Contractor for the following purposes (and for other agreed purposes or required by):
(a) the provision of Works; and/or
(b) analysing, verifying and/or checking the Client’s credit, payment and/or status in relation to the provision of Works; and/or
(c) processing of any payment instructions, direct debit facilities and/or credit facilities requested by the Client; and/or (d) enabling the collection of amounts outstanding in relation to the Works.
18.7 The Contractor may give information about the Client to a CRB for the following purposes:
(a) to obtain a consumer credit report;
(b) allow the CRB to create or maintain a credit information file about the Client including credit history.
18.8 The information given to the CRB may include:
(a) Personal Information as outlined in 18.3 above;
(b) name of the credit provider and that the Contractor is a current credit provider to the Client;
(c) whether the credit provider is a licensee;
(d) type of consumer credit;
(e) details concerning the Client’s application for credit or commercial credit (e.g. date of commencement/termination of the credit account and the amount requested);
(f) advice of consumer credit defaults, overdue accounts, loan repayments or outstanding monies which are overdue by more than sixty (60) days and for which written notice for request of payment has been made and debt recovery action commenced or alternatively that the Client no longer has any overdue accounts and the Contractor has been paid or otherwise discharged and all details surrounding that discharge(e.g. dates of payments);
(g) information that, in the opinion of the Contractor, the Client has committed a serious credit infringement;
(h) advice that the amount of the Client’s overdue payment is equal to or more than one hundred and fifty dollars ($150).
18.9 The Client shall have the right to request (by e-mail) from the Contractor:
(a) a copy of the Personal Information about the Client retained by the Contractor and the right to request that the Contractor correct any incorrect Personal Information; and
(b) that the Contractor does not disclose any Personal Information about the Client for the purpose of direct marketing.
18.10 The Contractor will destroy Personal Information upon the Client’s request (by e-mail) or if it is no longer required unless it is required in order to fulfil the obligations of this Contract or is required to be maintained and/or stored in accordance with the law.
18.11 The Client can make a privacy complaint by contacting the Contractor via e-mail. The Contractor will respond to that complaint within seven (7) days of receipt and will take all reasonable steps to make a decision as to the complaint within thirty (30) days of receipt of the complaint. In the event that the Client is not satisfied with the resolution provided, the Client can make a complaint to the Information Commissioner at www.oaic.gov.au.

19. Other Applicable Legislation
19.1 At the Contractor’s sole discretion, if there are any disputes or claims for unpaid Works and/or Materials then the provisions of the Building Industry Fairness (Security of Payment) Act 2017 (QLD) or the Building and Construction Industry Security of Payments Act 1999 (NSW) may apply.
19.2 Nothing in this Contract is intended to have the effect of contracting out of any applicable provisions of the Acts listed in clause 19.1 (each as applicable), except to the extent permitted by the Act where applicable.

20. Service of Notices
20.1 Any written notice given under this Contract shall be deemed to have been given and received:
(a) by handing the notice to the other party, in person;
(b) by leaving it at the address of the other party as stated in this Contract;
(c) by sending it by registered post to the address of the other party as stated in this Contract;
(d) if sent by facsimile transmission to the fax number of the other party as stated in this Contract (if any), on receipt of confirmation of the transmission;
(e) if sent by email to the other party’s last known email address.
20.2 Any notice that is posted shall be deemed to have been served, unless the contrary is shown, at the time when by the ordinary course of post, the notice would have been delivered.

21. Trusts
21.1 If the Client at any time upon or subsequent to entering in to the Contract is acting in the capacity of trustee of any trust (“Trust”) then whether or not the Contractor may have notice of the Trust, the Client covenants with the Contractor as follows:
(a) the Contract extends to all rights of indemnity which the Client now or subsequently may have against the Trust and the trust fund;
(b) the Client has full and complete power and authority under the Trust to enter into the Contract and the provisions of the Trust do not purport to exclude or take away the right of indemnity of the Client against the Trust or the trust fund. The Client will not release the right of indemnity or commit any breach of trust or be a party to any other action which might prejudice that right of indemnity;
(c) the Client will not without consent in writing of the Contractor (the Contractor will not unreasonably withhold consent), cause, permit, or suffer to happen any of the following events:
(i) the removal, replacement or retirement of the Client as trustee of the Trust;
(ii) any alteration to or variation of the terms of the Trust;
(iii) any advancement or distribution of capital of the Trust; or
(iv) any resettlement of the trust property.

22. General
22.1 The failure by either party to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect that party’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.
22.2 These terms and conditions and any contract to which they apply shall be governed by the laws of either Queensland or New South Wales, the state in which state the Works and/or Materials were provided by the Contractor to the Client however, in the event of a dispute that deems necessary for the matter to be referred to a Magistrates or higher Court then jurisdiction will be subject to the courts in the state of Queensland in which the Contractor has its principal place of business.
22.3 Subject to clause 14, the Contractor shall be under no liability whatsoever to the Client for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Client arising out of a breach by the Contractor of these terms and conditions (alternatively the Contractor’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Works).
22.4 The Contractor may licence and/or assign all or any part of its rights and/or obligations under this Contract without the Client’s consent.
22.5 The Client cannot licence or assign without the written approval of the Contractor.
22.6 The Contractor may elect to subcontract out any part of the Works but shall not be relieved from any liability or obligation under this Contract by so doing. Furthermore, the Client agrees and understands that they have no authority to give any instruction to any of the Contractor’s subcontractors without the authority of the Contractor.
22.7 The Client agrees that the Contractor may amend their general terms and conditions for subsequent future contracts with the Client by disclosing such to the Client in writing. These changes shall be deemed to take effect from the date on which the Client accepts such changes, or otherwise at such time as the Client makes a further request for the Contractor to provide Works to the Client.
22.8 Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.
22.9 Both parties warrant that they have the power to enter into this Contract and have obtained all necessary authorisations to allow them to do so, they are not insolvent and that this Contract creates binding and valid legal obligations on them.

© Copyright – EC Credit Control 1999 – 2019

What our happy customers say about us:

  • Thank you very much for a great job if you ever need a reference please have the customer contact me. Amazing is all I can say

    Client Richard Hoskins Rooty Hill
  • We had Elite Shower Repairs come to our home today to do a fix on one of our showers. We have been trying for a while to have someone come out but because it was a small job no-one seemed interested. Very professional & a great job done. Big thank-you to Barry. We highly recommend them.

    Client Deborah Waterworth Kellyville Ridge
  • My Bathroom and Balcony were just recently sealed. Not only were the jobs done and completed to perfection. Both areas were left clean and tidy. Barry respected my home. (taking shoes off on carpet) Barry also did extra bits like unblocking a pipe that he noticed was blocked to assist with water retention.
    It’s not often you find good trustworthy tradesman – who take pride in their work and go the extra mile. I was also able to leave him in my home while I took my kids to Sport. I would highly recommend Elite Shower Repairs.

    Client Julie Fenton Stanhope Gardens
  • Outstanding Service So pleased with the service provided to our shower. While we had a few other companies inspect, we chose Elite Shower Repairs as from the 1st phone call to the job being quoted, Staff was friendly and unlike others, I was asked many questions to ensure we saved money and didn’t get quoted for things that didn’t need doing. We were over the moon with the prompt efficient service. Once job was completed the bathroom was left spotless and shower looks new again. Thank you Elite.

    Client Icicle YT
  • Elite Shower Repairs provided such a great service that was efficient and done professionally. Barry the Technician was prompt and able to do a same day quote and booked in just a few days later. It made the shower look brand new! Would recommend Elite Shower Repairs to anyone requiring this kind of service. From a happy customer!

    Client Cecilienne-Mae Rooty Hill
  • Hi, Barry, Thanks for doing such a great job! The shower looks new again. The tiles have come up really well.

    Client Rita Killara
  • Great customer service and technicians attention to detail and work ethic was absolutely outstanding

    Client Kellie Weyman
  • Fantastic job done on our shower. Grout looks amazing and so glad it fixed our leaks! The quality is fantastic and the staff are very professional. Would definitely recommend to everyone!

    Client Monica Paine
  • Thankyou so much for the amazing work you’ve done for me and being so accommodating with time.
    I’ve always believed that great Customer Service is more important than the work itself but to get both at the high level you have provided is a first for me and I highly recommend you, your passion for what you do and your exceptional work. Thankyou

    Client Leanne Cash
  • Barry from Elite Shower fixed my leaking shower recess problem very efficiently. Both in the planning of the job and its execution, he provided excellent service at a reasonable price. He left the area clean as new. In fact, you wouldn’t know he had been except for the fact that the shower is now completely leak-free. Recommended TONY BOND EDGECLIFF

    Client Tony Bond Edgecliff
  • Simon did a terrific job. He was very professional and didn’t cut corners – e.g. it would have been easy to tile over waterproofing despite pinholes and save himself a Saturday but he did the right thing and reproofed. He turned up when he said he would and if there were unforseen delays,  he let me know in a timely manner.  I have recommended your service to a Real Estate agency, my neighbour and another  friend.  Barry’s advice was spot on – the tiles on the floor are great and the wall tiles almost match the others. Thank-you for a wonderful service and for your reliability

    Regards,
    Pam

    Client Pam Freeland
  • My showers look amazing!

    I am so pleased with the communication and professionalism.

    Never late and so tidy and clean.

    The price was worth it and yet not expensive.

    Client Diane Tam
  • From the initial call out and the efficient quoting process, to the high quality work, Barry and Melissa were a pleasure to deal with. We are very happy with the service and highly recommend them.

    Client Robert and Julijana

TRUSTED BY: